1.2 These Conditions are the only conditions upon which we are prepared to deal with you, and they shall govern the Agreement to the entire exclusion of any other express terms and conditions.
1.3 The headings in these Conditions are inserted only for convenience and shall not affect its construction.
1.4 In the event of a conflict between the provisions of these Conditions and the customer order form, the customer order form shall prevail unless otherwise expressly stated.
2. Basis of the agreement
2.1 In consideration of the payment of the Charges, we shall provide the Services and/or the Equipment subject to the terms and conditions set out in these Conditions.
3. Basis of this section
3.1 This Section B shall apply where you have asked us to design and develop your new Website as detailed in the customer order form (“the Website Service”).
4. Principal Duties
4.1 We shall from the Start Date:
4.1.1 Advise you in relation to all matters arising in the course of developing and installing your new Website and where appropriate recommend changes to the Specification;
4.1.2 Where necessary, design, write and supply Software to enable the Website to perform substantially in accordance with and conform substantially to the Specification; and
4.1.3 Provide the agreed User Training.
4.2 Any Content that you deliver or supply for inclusion in the Website must be delivered to us, where relevant, in the agreed format and you shall ensure that all such Content is correct and shall update it when we require you to do so.
4.3 Csharpmike reserves all rights to name the software it creates.
5.1 You shall provide us with all information, documentation and assistance that we reasonably request to enable us to properly provide the Website Service to you under the Agreement. We shall not be liable for any delay in the performance of the Website Service caused by any delay in providing, or inaccuracy of, any such information, documentation or assistance.
5.2 To facilitate our provision of the Website Service to you, you shall give our personnel such access to your personnel and premises as we may reasonably require to fulfil our duties and obligations. In particular, you shall make available sufficient working space and provide such facilities as we may reasonably require, and advise our personnel of the rules and regulations at your premises. You shall be responsible for the safety of all our employees and agents whilst on your premises for the purposes of providing the Website Service to you.
6.1 You may at any time by written notice request and we may at any time recommend variations to the Website or Specification.
6.2 Any amendment or variation to the Website or Specification may only be made with our prior written consent and we may levy an extra charge to you at our then standard hourly or daily rates (in addition to the Charges) to reflect the cost and expenses of any additional work required by us to provide such amendment or variation.
7.1 At each agreed milestone we shall submit for your written approval the elements of the Website that we have designed and developed to meet that milestone. Your written approval of our work shall be your acceptance that those elements of the Website conform substantially with the Specification.
7.2 Prior to, or following, delivery of the Website, we shall carry out our standard acceptance tests, or ensure that they are carried out.
7.3 If the Website materially fails our standard acceptance tests and on investigation this proves to be as a result of an error by you, we shall be entitled to charge for the costs of the investigation and making the necessary changes to the Website at our then current hourly or daily rates. If the Website materially fails to pass our standard acceptance tests for any other reason, we shall (without extra charge) determine the causes of the failure, advise you of them and make any changes to the Website necessary to ensure that the Website will pass our standard acceptance tests. Following the making of any such changes, we will repeat or procure the repetition of our standard acceptance tests as is necessary to ensure successful completion of them.
7.4 We shall use all reasonable endeavours so that successful completion of the Website Service occurs in accordance with the development timetable but all milestone delivery dates are non-binding estimates. Time shall not be of the essence in the provision of the Website Service or any part thereof and we shall not be liable for the consequences of any delay in its or their provision.
7.5 Risk of loss or damage to the Website, the Software, the Content and/or the Documentation shall pass to you upon successful completion of the acceptance tests. Where acceptance tests have not been agreed by us in writing, such risk of loss or damage shall pass to you upon delivery of the Website to you.
8. Basis of this section
8.1 This Section C shall apply where you have asked us to provide a hosting service for your Website (“the Hosting Service”).
9. Our Rights And Obligations
9.1 We shall install or arrange the installation of your Website on the Server and make your Website available to the public via a connection to the Internet.
9.2 In the event that access to your Website exceeds the permitted bandwidth, storage allocation or both (as notified to you), we shall be entitled, in our absolute discretion: to (i) suspend access to the Website; or (ii) move the Website to a different server and/or increase the Charges for the Hosting Service commensurately.
9.3 Notwithstanding any other provision in the Agreement, we shall be entitled without notice and at any time, to change the permitted bandwidth or storage allocation for your Website or make any other change to the Hosting Service: (i) required to comply with safety, security or other applicable legal requirements; or (ii) which does not materially effect the quality or nature of the Hosting Service.
9.4 We may subcontract the provision of the Hosting Service under Condition 32.1.
10.1 You undertake to ensure compliance with our Code of Conduct in relation to all usage of your Website. We are entitled at any time, without notice and without liability, to remove your Website from the Server or bar or restrict access to your Website in the event of any breach or alleged or suspected breach of the Code of Conduct in relation to your Website or if otherwise authorised to do so by a law enforcement agency.
10.2 You undertake that any material contained in or linked to your Website and (if applicable) contained in any discussion group, forum, chat room or bulletin board on your Website (“Material”) is and shall remain: (i) legal, decent, honest and truthful; and (ii) compliant with the Personal Information Protection and Electronic Documents Act 2004 (Canada) and all other applicable laws and regulations from time to time.
10.3 You shall: (i) ensure at all times the accuracy, lawfulness, currency and legislative and regulatory compliance of the Material and the Website; and (ii) be solely liable for any faults or misleading, inaccurate, infringing, defamatory or otherwise unlawful or actionable material contained or referred to in the Website.
10.4 You are solely responsible for maintaining the confidentiality and security of your Internet accounts and usage, including use of your unique log-on ID.
10.5 You acknowledge and agree that we may be required by a law enforcement agency or for any other legal or regulatory purposes: (i) to monitor the Content and traffic on your Website; and (ii) where necessary to support or defend any dispute, action, cause or other matter that arises, to give evidence of your use of your Website or allow use of your unique log-on ID.
11.1 The Hosting Service shall commence on the Start Date and continue for the Initial Period, unless terminated sooner in accordance with the Agreement. After the Initial Period the Agreement shall continue unless and until terminated by either of us giving Due Notice in writing to the other. Due Notice to terminate the Agreement cannot be served until the Initial Period has elapsed.
12.1 We do not warrant that access to the Website will be uninterrupted or error free but we shall use reasonable endeavours to keep downtime to a minimum. We shall make all commercially reasonable efforts to provide you with email notification of all scheduled and emergency outages.
12.2 Where we subcontract the provision of the Hosting Service under Condition 32.1, we will not have control of the Server and accordingly shall not be liable for any loss (including, without limitation any indirect consequential or special loss, damage, costs or expenses or other liability incurred as a result (directly or indirectly) of: (i) Server downtime; (ii) inability to access the Website; (iii) loss of or damage to any files, data or the Website; and (iv) any non-receipt, misrouting or failure of email or other message transfer, except to the extent that: (i) the subcontractor accepts such liability under the relevant subcontract with us; and (ii) we are actually indemnified for such liability.
12.3 We provide 12 months website technical support and warranty of our work, free of charge, from the date of your website launch. For the avoidance of doubt, we do not support any third party software on your website, or any web design, web development or web programming works undertaken on your website unless it is undertaken by us. In the case where your website has been worked on by other parties, we have the right to terminate any technical support and warranty with immediate effect.
12.4 If you are taking out a technical support contract with us for your website, it is your responsibility to inform us beforehand, by e-mail or letter, whether anyone else has carried out work on your website. We have a right to refuse the provision of a technical support contract, or terminate an existing technical support contract, where a website have been worked on by anyone else other than us.
12.5 Any website technical support contract or website warranty provided by us to you does not include software updates to your website eg. latest version releases for both in-house or open source software.
13.1 For the avoidance of doubt, we do not monitor and will not have any liability for the content of any communication transmitted by virtue of the Hosting Service.
13.2 Due to the public nature of the Internet, we shall not be liable for the protection of the privacy of electronic mail or any other information transferred through the Internet or via any network provider and no guarantee or representation is given that the Hosting Service will be free from hackers or unauthorised users. You shall be liable for the content of any emails transmitted by virtue of the Hosting Service and for ensuring that they comply at all times with all relevant legislation (including, but not limited to the Personal Information Protection and Electronic Documents Act 2004 (Canada) and all other privacy laws, regulations and guidance notes made or issued thereunder).
13.3 You grant us a non-exclusive, royalty free licence for the term of the Agreement to use, store and maintain the Content contained in your Website on the Server for the purposes of providing the Hosting Service. We may make such copies as may be necessary to perform our obligations including back-up copies of the Content.
14.1 Unless otherwise agreed in writing with you, we shall not be responsible for altering, modifying or updating the Website or its Content or any liability that may arise as a result of any such alterations, modifications or updating.
15. Basis for this section
15.1 This section D shall apply where you have asked us to supply and/or install the Equipment.
16.1 We agree to: (i) sell the Equipment to you free from encumbrances; and (ii) where agreed in writing with us, install the Equipment at the agreed premises on the agreed installation date.
16.2 We reserve the right, prior to delivery of the Equipment, to substitute an alternative item of equipment for any item of equipment that we have agreed to supply to you provided that the functionality of the alternate equipment will not materially differ in performance to the substituted equipment and will not result in any increase in the Charges.
16.3 Operating supplies such as tapes, disks, stationery, printing ribbons and similar accessories are not supplied as part of the Equipment.
17.1 We shall submit the Equipment to our standard works tests before delivery to you.
17.2 The Charges do not include the cost of transportation of the Equipment to your premises. You will pay for the cost of such delivery in addition to the Charges.
17.3 You shall, at your own expense, prepare your premises to provide proper environmental and operational conditions for the installation and operation of the Equipment prior to delivery and installation.
17.4 We shall install the Equipment at the premises on the installation date. If, in our reasonable opinion, it is necessary to remove or otherwise disconnect any of your existing equipment at the premises in order to carry out the installation of the Equipment, then you shall permit and obtain all necessary consents for such removal and/or disconnection and shall give us all necessary assistance to enable such work to be carried out.
17.5 We shall upon installation submit the Equipment to our standard installation test to ensure that the Equipment and every part thereof is in full working order. We shall supply to you copies of the results of such tests. The Equipment shall be deemed to have been accepted once our installation tests have been passed.
18.1 The title to the Equipment shall pass to you on payment in full of the Charges and any other sums that may then be due under this Agreement. If you do not pay to us the Charges in full by the due date we shall be entitled to re-take possession of the Equipment by giving you at least 7 days written notice and you hereby grant us a licence to enter any premises controlled by you for the purpose of so recovering.
18.2 Risk in the Equipment shall pass to you on delivery of the Equipment to your premises. Accordingly you shall be responsible for insuring the Equipment against all normal risks with effect from the time risk in the Equipment passes to you under this Condition 18.2.
19.1 In this Condition 19, the expression "Relevant Equipment" means any part of the Equipment which is intended to be connected to any telecommunication system which is or is to be connected to a public telecommunication system.
19.2 If you connect the Relevant Equipment to any telecommunication system, you shall be responsible for obtaining the consent of the owner of that system (if necessary) to such connection and for complying with all conditions relating thereto.
19.3 You undertake that you will not make any modification to the Relevant Equipment without our prior written consent.
19.4 Where we give any data transmission speeds in relation to the Equipment, such speeds are at all times subject to any conditions attached to the use of the relevant modem or telecommunication equipment at the speeds indicated and to the capability of such modem or other telecommunication equipment to achieve such speeds.
19.5 We do not give any warranty that the Equipment is fit for any particular purpose unless that purpose is specifically advised to us in writing and we confirm in writing that the Equipment can fulfil that particular purpose.
19.6 Any warranty confirmed in writing by us under Condition 19.5 or 20.1 is contingent upon your proper use of the Equipment and does not cover any part of the Equipment which has been modified without our prior written consent or which has been subjected to unusual physical or electrical stress or on which the original identification marks have been removed or altered. Nor will the warranty apply if repair or parts replacement is required as a result of causes other than ordinary use, including without limitation, accident, hazard, humidity control or other environmental conditions.
20.1 We do not warrant that the Equipment will achieve any particular performance criteria unless: (i) we have specifically guaranteed such criteria in writing subject to specified tolerances; and (ii) the environmental conditions we specify are maintained.
21. Charges and payment
21.1 In consideration of the performance of our duties under the Agreement you shall pay to us the Charges.
21.2 We may invoice you at periodic intervals, as we consider appropriate before final completion of the Services. An interim invoice represents our final charge of for work up to the date of the invoice, unless we tell you otherwise at the time.
21.3 We shall be entitled, at our absolute discretion but not without valid reason (including, without limitation, to reflect changing arrangements with any subcontractor or third party supplier or changing legal, regulatory or business requirements), to increase the Charges for the Hosting Service by giving 8 weeks written notice to you.
21.4 The Charges are inclusive of all labour but exclude: (i) value added tax which if payable shall be charged to you and (ii) agreed expenses as detailed in the customer order form.
21.5 All payments to us by you for web site deposits, web site balances, SEO services shall be made immediately upon receipt of invoice, all other invoice payments to us by you shall be made within 14 days unless otherwise. All payments made by you shall be in pounds sterling and shall be made by cheque or bank transfer to such bank account as is nominated by us in writing. Time for payment shall be of the essence.
21.6 The Charges shall be exclusive of all travel, accommodation and subsistence expenses incurred by our personnel in providing the Services and/or the Equipment, which shall be invoiced separately.
21.7 If the Charges or any other money owing to us is not paid by you by the due date we reserve the right to: (i) suspend our performance of the Services and/or supply of the Equipment or suspend your access to your Website until the Charges (and any interest payable thereon) is paid; and/or (ii) charge you interest on the overdue amount(s) at the rate specified in the Late Payment of Commercial Debts (Interest) legislation.
21.8 For SEO contracts if payments have been made by credit card through our website these details are stored with SagePay in accordance with the PCI compliance regulations. For consecutive month there after and for the duration of the SEO contract we shall manually take repeat payments from the credit card.
22.1 Where you contract for us to arrange for a domain name registration, we shall endeavour to procure the registration as you request in writing. However, we shall not be liable in the event that the relevant domain name regulatory authority refuses to register the domain name, or suspends or revokes any registration. We shall not act as your agent or on your behalf in any dealings with regulatory authorities.
22.2 The registration of a domain name and its ongoing use is subject to the relevant naming authoritys terms and conditions of use which you should obtain and consider. You are responsible for ensuring that you are aware of these terms so that you can comply with them. It is your responsibility to ensure that your domain name registration is renewed on its renewal date in accordance with such terms. If you do not pay the renewal fee for your domain name re-registration by the specified date on invoices then we will not be liable in any way if the domain name renewal lapses.
22.3 We shall have the absolute discretion to require you to select a replacement name and may suspend our performance of the Services if, in our opinion, there are reasonable grounds for us to believe that your current choice of name is, may or is likely to be in breach of the provisions of the Agreement or any legal or regulatory requirement.
22.4 You confirm and warrant that: (i) you are the legal owner of any name supplied by you for use as a domain name in connection with the Website (or have the authority of the legal owner to use such name); (ii) that such use of name does not infringe the rights of any third party; and (iii) that you are the owner of any trademark in any such name (or have the authority of the owner of any trademark to use such name).
23.1 You acknowledge that you have no right, title or interest in any internet protocol address (“IP address”) allocated to you, and that any IP address allocated to you is allocated as part of the Services and is not portable or otherwise transferable by you in any manner whatsoever.
23.2 If an IP address is re-numbered or re-allocated by us, we shall use our reasonable endeavours to avoid any disruption to you.
23.3 You agree that you shall have no right, title or interest to any IP address upon termination of the Agreement, and that the acquisition by you of a new IP address following termination of the Agreement shall be solely your responsibility.
24.1 All IPR in the programming, tools, skills, coding and techniques we acquire in developing the Website or any part thereof or otherwise in performing the Services are owned by and shall belong to us and we shall be free to use and adapt any or all of the same in or for the purposes of any other project(s).
24.2 All IPR in: (i) the design of and data incorporated in the Website; and (ii) any Content we develop or supply and any New Software we create under or as a result of the Agreement or otherwise in the provision of the Services; are owned by and shall belong to us. Subject to Condition 24.4, we grant to you a non-exclusive, royalty free, non-transferable, perpetual licence to use the IPR referred to in this Condition 24.2 (but not the IPR referred to in Condition 24.1) in connection with the Website.
24.3 You may not decompile, disassemble or reverse engineer the Website or any Software except to the extent permitted by law or with our prior written consent.
24.4 Without prejudice to any other rights available to us, we may terminate the licence granted under Condition 24.2 if you fail to pay any sum due to us on its due date for payment.
24.5 You hereby authorise us to publish on the Internet all materials supplied or authorised by you for inclusion on the Website.
24.6 You grant us a non-exclusive, royalty free licence to use for the purposes of this Agreement: (i) the IPR in any Content you develop or supply for inclusion on the Website; and (ii) any other IPR owned by you that we require for provision of the Services.
25.1 Each of us (the “indemnifying party”) agrees to indemnify the other (the “innocent party”) against any liability, loss, costs and damage suffered by the innocent party as a result of any third party IPR infringement claim made against the innocent party in respect of: (i) the innocent partys use (pursuant to this Agreement) of any IPR licensed to the innocent party by the indemnifying party under this Agreement; or (ii) any breach of any warranty given in Condition 22.4. This indemnity is conditional upon the innocent party seeking to enforce this indemnity:
25.1.1 giving written notice to the indemnifying party as soon as reasonably possible after it has received written notice of the threat or existence of any such threat.
25.1.2 making no statement or admission of liability in respect of the claim and giving the indemnifying party sole authority to defend or settle the claim at the indemnifying partys cost and expense.
25.1.3 giving all reasonable assistance requested by the indemnifying party in connection with defending or settling the claim (at the indemnifying partys cost and expense).
25.1.4 not having caused or contributed to the cause of the claim by using the indemnifying partys IPR other than in accordance with the terms of the Agreement.
25.2 The indemnity in Condition 25.1 shall not apply where the third party IPR infringement claim results from: (i) any alteration or modification to the Website, the Content or the Software (“the Package”) or any part of the Package made by you or on your behalf by any third party or us at your request, or (ii) your use of the Package or any part of it in combination with hardware or software not supplied or approved by us or for any purpose not envisaged in the Specification.
26.1 Our Software, Third Party Software and any New Software to be used in conjunction with the Website shall be licensed to you on our standard software licence terms or the standard software licence terms of the owner of the IPR in the Third Party Software, (as the case may be).
26.2 Unless agreed in writing, we will not be responsible for upgrading your website with the latest version of open source or in-house software.
26.2.1 Any warranty or support contract that we provide you with does not include upgrading your website with the latest version of open source or in-house software.
26.3 We can install your website with additional legitimate and secure external software/plugin if requested by you at an additional cost. The cost to use any external software/plugin (one off payment or recurring) must be paid by you directly to the third party software supplier, unless agreed otherwise in writing by us.
26.3.1 Any website warranty or technical support contract we provide you with does not include work to further upgrade that external software/plugin to the latest version. Neither does that warranty or technical support contract cover work needed to rectify website errors as a result of you undertaking software/plugin upgrades yourself.
27.1 We warrant and represent to you:
27.1.1 that the Services shall be provided with reasonable care and skill, in accordance with usual industry procedure and in a timely, workmanlike and effective manner.
27.1.2 the Website shall conform substantially to the Specification after successful completion of any agreed acceptance tests.
27.1.3 where supplied and/or installed by us, the Equipment will be free from defects in material workmanship for a period of 12 months after the installation date or delivery date (as the case may be). This warranty is contingent upon your proper use of the Equipment and does not cover any part of the Equipment which has been modified without our prior written consent or which has been subjected to unusual physical or electrical stress or on which the original identification marks have been removed or altered. Nor will the warranty apply if repair or parts replacement is required as a result of causes other than ordinary use, including without limitation, accident, hazard, humidity control or other environmental conditions.
27.2 Our sole obligation in respect of a breach of warranty contained in Condition 27.1 shall be to investigate and, at our option, remedy the defect by repeating the Services or refunding an appropriate part of the Charges, or repairing or replacing the Equipment (or relevant part thereof). Title to any replaced Equipment or any defective part thereof shall revert back to us upon the replacement of the Equipment or defective part.
27.3 We shall have no liability or obligation under the warranty in Condition 27.1 unless we have received written notice of the default, defect or error in the provision of the Services and/or the Equipment in question no later than the expiry of 3 months after the date on which the default, defect or error came to the your attention, or should have come to your attention. Any such notice must detail an example of the default, defect or error in question and how provision of the Services and/or the Equipment in question should have occurred.
27.4 As per Condition 12.3 we have the right to terminate any warranty with immediate effect when your website has been worked on by anyone else other than us.
27.5 Except as expressly set out in these Conditions, all representations, warranties, terms and conditions, whether oral or written, express or implied by law, custom, statute or otherwise, and including but not limited, to satisfactory quality or fitness for any particular purpose, are excluded to the fullest extent permitted by law.
28.1 We shall not be liable for any defects in the Website or Equipment or any component parts which arise as a result of: (1) use of the Website in conjunction with software or systems not expressly notified to you by us in writing or for any purpose not envisaged in the Specification; (2) defects, faults or individual workings of your systems; (3) misuse, alteration, maintenance or interference by you or any third party (including virus and hacker attacks); (4) environmental conditions; or (5) power failure, power fault or electrical interference.
28.2 Not with standing any other provision of the Agreement, our liability to you for death or personal injury resulting from our negligence or for fraudulent misrepresentation shall not be excluded or in any way limited.
28.3 Our maximum aggregate liability under or in connection with the Agreement, whether in contract, tort (including negligence) or otherwise, shall in no circumstances exceed the higher of (a) the Charges payable to us under the Agreement or (b) the proceeds received by us under our professional indemnity insurance policy in respect of the liability in question.
28.4 Unless otherwise provided in the Agreement, we shall not be liable to you for any increased costs or expenses, loss of profit, business, contracts, revenues or anticipated savings or loss of software, application programs or computer held data or any indirect, consequential or special loss of any kind, howsoever arising and whether caused by our negligence or otherwise, which may be suffered by you and arise out of or in connection with the supply of the Services and/or Equipment or their use.
29.1 Each of us shall treat as confidential all information obtained from the other under or in connection with the Agreement.
30.1 Unless terminated in accordance with your right under clause 30.3 or as otherwise provided in the Agreement, you may not terminate the Agreement at any time except with our prior written consent and, only then, if you indemnify us in full against all loss (including, without limitation, loss of profit), costs, damages, charges and expenses we reasonably incur as a result of such early termination.
30.2 Notwithstanding clause 30.1 if: (i) you have asked us to provide you with the Website Service; (ii) we have agreed to do so subject to the terms and conditions of the Agreement; and (iii) you cancel the Agreement for any reason at any time prior to our completion of the design and development of your new Website in accordance with the Specification, you shall be liable to pay us a percentage of the Charges payable for the Website Service to compensate us for the losses, costs and expenses incurred by us in connection with our supply of the Website Service to you up to the date you cancel the Agreement. The following percentages shall be payable unless the total losses, costs and expenses that we have incurred are less, in which case we shall only be entitled to recover that lesser amount: All cancellation fees payable under this clause 30.2 will be deducted from any deposit paid by you in respect of the Agreement. If your deposit: (i) is greater than the applicable cancellation fees we will refund the balance to you; or (ii) is less than the applicable cancellation fees you will be required to pay the outstanding amount over and above your deposit within 14 days of the date you cancel the Agreement. Where you fail to pay the outstanding amount within this 14-day period, we shall (without prejudice to any other rights or remedies available to us) be entitled to charge you interest on the amount outstanding in accordance with Condition 21.7.
30.3 Either of us may immediately terminate the Agreement by notice to the other if the other:
30.3.1 is in breach of a material obligation under the Agreement and, if the breach is capable of remedy, fails to remedy the breach within 30 (thirty) days starting on the day after receipt of notice giving details of the breach and requiring the breach to be remedied. For the avoidance of doubt a failure by you to pay the Charges by the due date shall be a material breach that is not capable of being remedied; or
30.3.2 commits any act of bankruptcy or compounds with its creditors, or a petition or a receiving order in bankruptcy is presented or made against it, or a petition for an administration order is presented in relation to it, or a resolution or a petition to wind up is presented otherwise than for a solvent re-construction or amalgamation, or a receiver, administrative receiver or administrator is appointed.
30.4 Immediately on termination of the Agreement for any reason you shall pay us for work undertaken on your behalf prior to termination at our then standard hourly or daily rate, together with any indemnity due under Condition 30.1 in the event of early termination.
30.5 All obligations contained in the Agreement that are expressed or may be implied to continue beyond the expiry of the Agreement shall continue to bind the parties notwithstanding termination.
31.1 You shall not assign, transfer or in any other manner make over to any third party the benefit and/or burden of the Agreement without our prior written consent, which shall not be unreasonably withheld.
32.1 We may in whole or in part assign, transfer, delegate, subcontract or in any other manner make over to any third party any of our rights or obligations under the Agreement at any time.
32.2 If at any time we subcontract any of our obligations under the Agreement, we shall not be liable for any act or omission of the subcontractor, except to the extent that: (i) the subcontractor accepts liability for such act or omission under the relevant subcontract with us; and (ii) we are actually indemnified for such liability.
33.1 Neither of us shall be deemed to be in breach of the Agreement or otherwise liable to the other for any delay in performance or any non-performance of any obligations under the Agreement if and to the extent that the delay or non-performance is due to an event or circumstance beyond the reasonable control of that party.
34.1 No failure, delay or partial exercise on the part of either of us in exercising any right, power or privilege under the Agreement shall operate as a waiver of it, nor shall it preclude any other or further exercise of it.
34.2 Except as otherwise expressly agreed in writing you shall have no rights of set-off, abatement or withholding (statutory or otherwise).
34.3 If any provision of the Agreement is held to be void or declared illegal, invalid or unenforceable for any reason whatsoever, that provision shall be divisible from the Agreement and shall be deemed deleted from the Agreement and the validity of the remaining provisions shall not be affected.
34.4 Any notice shall be delivered personally or prepaid first class post (air mail if posted to or from a place outside Canada) or by fax or email (if a confirmation or delivery report is received) to the address, fax number or email address provided for such purposes.
34.5 The Agreement embodies and sets forth our entire agreement and understanding and supersedes all prior oral or written agreements, representations, understandings or arrangements relating to the subject matter of the Agreement. Neither of us shall be entitled to rely on any agreement, representation, understanding or arrangement not expressly set forth in the Agreement save for any representation made fraudulently.
34.6 The Agreement shall be governed by and construed in accordance with the laws of Canada and the parties irrevocably submit to the exclusive jurisdiction of the courts of Canada.
34.7 The Contracts (Rights of Third Parties) Act 1999 shall not apply to the Agreement and no person other than the parties to the Agreement shall have any rights under it, nor shall it be enforceable under that Act by any person other than the parties to it.
34.8 We perform all of our obligations under the Agreement as an independent contractor and nothing in the Agreement shall create or be deemed to create a partnership, joint venture of the relationship of principal and agent or employer and employee.
34.9 No variation of the Agreement shall be valid unless it is in writing and signed by or on behalf of each party. Time at which the Agreement is cancelled: Percentage of Charges payable: At any time prior to the first visit of our website Designer 30% At any time after the first visit of our website designer but before our completion of the design and development of your new Website The actual cost incurred by us up to a maximum of:100%
35.1 We do not allow Adult, Warez, illegal MP3 Sites or IRC Bots.
35.2 You may not store more data in your account than your allotted virtual server space.
35.3 Your virtual server (inc FTP and Telnet access) is for your personal use only. You must not divulge the password to any other person, and you should take reasonable precautions to ensure that it is not discovered by other people.
35.4 Data stored on our servers is only backed up once a day. It is recommended that you keep an independent backup of all data stored on your virtual server.
35.5 You may not run server processes (eg. talkers/IRC Bots) from your virtual server. We shall not be held liable for any loss or damages caused by the use or misuse, unavailability or removal of services.
35.6 When your account is closed, all files (including web pages, etc.) will be deleted.
35.7 We reserve the right to cancel your account at any time without notice.
35.8 We reserve the right to amend and update these Terms and Conditions at any time without notice.
35.9 To protect your privacy we never distribute your name or e-mail address to any third parties.
35.10 Users must not participate in any form of unsolicited bulk e-mailing or spam.
35.11 By logging into your account, or uploading files to it, you are indicating your acceptance of these Terms and Conditions.